This Disclaimer applies to all information published on RealEstateIQ™ ("we", "us", "the Platform"). It has two parts: Part A – RERA Project & Builder Data and Part B – Livability Data. By using the Platform you acknowledge that you have read and understood both parts. It should be read together with our Terms of Service and Privacy Policy.
A1. Source of information
Project, promoter (builder / developer), agent, unit, litigation, quarterly-update and compliance information shown on the Platform is collected from records that are publicly available on the website of the Chhattisgarh Real Estate Regulatory Authority (CG-RERA) and other public sources such as town & country planning notices. We do not create, verify, certify or endorse the original filings.
A2. No affiliation with any authority
RealEstateIQ™ is an independent private platform. We are not a government body and are not affiliated with, authorised, endorsed or sponsored by CG-RERA, any other RERA, the Government of Chhattisgarh or any government department. Use of names, logos or registration numbers is only for identification of public records.
A3. Accuracy, completeness and timeliness
- Data may be incomplete, delayed, duplicated, mis-matched or out of date. Promoters may revise or withdraw filings at any time, and the authority may update or remove records without notice.
- Data is refreshed periodically, not in real time. The “data as of” date shown on the Platform is indicative only.
- Automated collection, matching of names and conversion of formats can introduce errors, including wrong project-to-builder mapping, wrong dates, area figures, unit counts or status.
- The official RERA portal and the registered documents are the only authoritative source. If there is any difference, the official record prevails.
A4. Trust Scores, ratings, rankings and indicators
Trust Scores, risk flags, delay indicators, grades, rankings and similar metrics are algorithmically computed opinions derived from publicly disclosed data and the methods described on our Methodology page. They:
- are statistical indicators, not statements of fact about any person or entity;
- do not assess the legal title, construction quality, financial health, intent or future performance of any builder or project;
- may change as data or methodology changes, and may not reflect events not yet filed with the authority;
- are not a recommendation to buy, sell, book, invest in or avoid any property, project or builder.
A5. Project and builder specific disclaimers
- Project status: Registration, completion, extension, lapse, revocation and “ongoing / completed” labels reflect the last data we received and may not show recent orders or actions.
- Timelines and delays: Proposed and revised completion dates are as declared by the promoter. Delay figures are computed from those declarations and may not account for force majeure, regulatory extensions, stay orders or agreed changes.
- Units, inventory and pricing: Unit counts, sold / unsold status, carpet area, rates and price ranges are promoter-declared or estimated and may differ from actual availability, final price, taxes, charges or agreement terms. Nothing on the Platform is an offer or price quotation.
- Promoter and builder profile: A builder’s past-project count, experience, litigation and complaint information is aggregated from public records and may be incomplete or attributed to a related entity by mistake. A promoter entity, its partners, directors and group companies may differ.
- Litigation and complaints: The existence or absence of a case, complaint or order does not indicate guilt, liability or outcome. Cases may be settled, withdrawn, stayed or decided after our last update. We do not publish allegations as findings.
- Financial and escrow data: Figures on fund utilisation, bank accounts, CA / architect / engineer certificates and quarterly progress are as filed and are unaudited by us.
- Approvals and documents: Mention of sanction, layout, environmental or other approvals, or display of documents, does not confirm their validity, currency or compliance. Always inspect originals.
- Agents and channel partners: Listing of a registered agent or channel partner is informational and not an endorsement of their services.
- Buyer reviews and user content: Reviews, ratings and feedback are opinions of their authors, are not verified by us, and do not represent our views.
- Future / upcoming projects: Information on proposed or pre-launch projects is based on public announcements and notices; such projects may not receive approval, may change, or may never launch.
- Maps and locations: Project and builder locations, boundaries and distances are approximate and must not be used for legal demarcation or site identification.
A6. Not advice
Content on the Platform is for general information and research only. It is not legal, financial, investment, tax, valuation or real-estate-broking advice, and no advisor–client or broker relationship is created. Before booking or buying any property, you should independently verify the project and promoter on the official RERA portal, check title and approvals through a qualified lawyer, inspect the site, read the agreement for sale, and consult professional advisers.
A7. Limitation of liability
To the fullest extent permitted by law, RealEstateIQ™, its owners, employees and partners are not liable for any direct, indirect, incidental, consequential or financial loss, loss of opportunity or damage arising from use of, or reliance on, the RERA data, scores or any content on the Platform, or from any decision taken on that basis. You use the Platform at your own risk. Information is provided “as is” and “as available” without warranties of any kind.
A8. Corrections and takedown requests
If you are a promoter, agent or other person named on the Platform and believe any information is wrong or outdated, please write to us with the project / registration number and supporting documents (such as a RERA certificate or order). We will review and correct verified errors within 5–7 business days. Corrections do not amount to an admission of any claim, and we may rely on the official RERA record.
B1. Nature of the data
Livability scores, area rankings, sub-scores and related maps (for example for infrastructure, connectivity, healthcare, education, amenities, air quality, green cover, flood / water-logging, built-up density, noise and safety) are modelled estimates for neighbourhoods and sectors. They are produced from a mix of open and third-party sources, which may include OpenStreetMap, Google Maps / Places, satellite and remote-sensing datasets (such as Earth Engine and Open Buildings), air-quality feeds, government and municipal data, and our own surveys and assumptions.
B2. Limitations
- Third-party data can be missing, outdated, crowd-sourced or inaccurate, and coverage differs from area to area.
- Scores are relative comparisons using our weights and methodology; they are not absolute measures and may rank an area differently from your personal priorities.
- Distances, travel times, counts of facilities and boundaries are approximate. Facilities may have opened, moved or closed.
- Air quality, flooding, heat and noise indicators are point-in-time or averaged values and do not predict future conditions or health impact.
- Road, metro, BRTS, expressway, township and other infrastructure shown may be proposed or under construction; timelines and alignments can change and are not guaranteed.
- Rental, price-trend and cost-of-living figures are indicative estimates from surveys and public listings, not valuations.
- Official ward, sector or zone boundaries may differ from those drawn on our maps.
B3. No guarantee or advice
Livability information is general guidance only. It is not a guarantee of quality of life, safety, resale value, appreciation, rental yield or suitability of any location, and is not a valuation, planning, environmental, health or investment opinion. Please visit the area, speak to residents and consult qualified professionals before relying on it.
B4. Third-party sources and trademarks
Third-party names, data and map content remain the property of their respective owners and are subject to their own licences and terms. Their use on the Platform does not imply endorsement by or affiliation with those parties.
B5. Limitation of liability
The limitation of liability in clause A7 applies equally to Livability data. We are not responsible for any loss or decision arising from reliance on livability scores, rankings, maps or reports, whether free or paid.
We may update this Disclaimer from time to time; the latest version on this page applies. If any part is held unenforceable, the rest remains in effect. This Disclaimer is governed by the laws of India and, subject to applicable law, the courts at Raipur, Chhattisgarh shall have jurisdiction.